Terms of Service

1. Acceptance of Terms

By accessing our website, submitting a project inquiry, or entering into a service agreement with us, you acknowledge that you have read, understood, and agree to be bound by these Terms of Service. If you do not agree with any part of these Terms, you must not use our website or engage our services.

These Terms apply to all visitors, clients, contractors, and any other parties who access or use our services. If you are entering into these Terms on behalf of a business or legal entity, you represent that you have the authority to bind that entity to these Terms.

2. Services Description

Turnkey Online Casino provides custom software development services focused on building online casino platforms. Our services include, but are not limited to:

• Design, development, and deployment of fully custom online casino platforms tailored to each client's specifications.
• Integration of third-party game providers, payment gateways, and ancillary systems as required by the project scope.
• Back-office and administrative panel development for platform management, player management, and reporting.
• Technical consultation, platform architecture planning, and technology stack advisory services.
• Post-launch support, maintenance, and iterative feature development as agreed upon in individual service contracts.

We are a software development company. We do not operate online casinos, accept wagers, process gambling transactions, or provide gambling services to end users. Our clients are solely responsible for obtaining all necessary licenses, permits, and regulatory approvals to operate their platforms in their respective jurisdictions.

3. Client Obligations

By engaging our services, you agree to the following obligations:

• Lawful Use: You are solely responsible for ensuring that the platform we build for you is operated in full compliance with all applicable laws, regulations, and licensing requirements in every jurisdiction where it is made available.
• Accurate Information: You agree to provide accurate, complete, and timely information, materials, and feedback necessary for us to perform our development work effectively.
• Cooperation: You agree to cooperate with our development team, participate in scheduled reviews and approvals, and respond to requests for clarification or decisions within reasonable timeframes.
• Access and Resources: You agree to provide any required access to third-party systems, accounts, APIs, or resources necessary for integration work as outlined in the project scope.
• Non-Interference: You agree not to reverse-engineer, decompile, or attempt to extract the source code of any proprietary tools, frameworks, or libraries used in the development process unless expressly permitted under a separate license agreement.

4. Intellectual Property and Ownership

Intellectual property rights related to our services are governed as follows:

• Client Deliverables: Upon full payment of all fees due, ownership of the custom code, designs, and assets created specifically for your project ("Deliverables") will transfer to you as outlined in your service agreement.
• Company Tools and Frameworks: We retain all rights, title, and interest in any pre-existing tools, libraries, frameworks, modules, or proprietary technologies that we use or incorporate into your project. These remain our intellectual property and are licensed to you solely for use within the delivered platform.
• Third-Party Components: Any third-party software, plugins, or services integrated into your platform are subject to their respective licenses and terms. We do not transfer ownership of third-party intellectual property.
• Portfolio Rights: Unless otherwise agreed in writing, we reserve the right to reference the project in our portfolio, case studies, and marketing materials in general terms, without disclosing confidential information.

5. Payment Terms

Payment terms for our services are governed by the individual service agreement or statement of work executed between you and us. The following general terms apply:

• Project fees, payment schedules, and milestone structures will be defined in your service agreement prior to work commencing.
• A non-refundable deposit may be required before development begins, as specified in your agreement.
• Invoices are due within the timeframe specified in your service agreement. Late payments may incur interest charges at the rate stated in your agreement, or at the maximum rate permitted by applicable law.
• We reserve the right to suspend or halt work on any project for which payment is overdue by more than fifteen (15) business days, until all outstanding balances are settled.
• Additional work, change requests, or scope expansions beyond the original agreement will be quoted separately and require written approval before implementation.

6. Project Timeline

Estimated project timelines and delivery dates are provided in good faith based on the agreed scope of work. While we make every reasonable effort to meet projected deadlines, timelines are estimates and not guarantees. Delivery schedules may be affected by:

• Delays in receiving required information, feedback, approvals, or materials from the client.
• Changes to project scope, requirements, or specifications requested by the client after work has commenced.
• Third-party dependencies, including delays from payment providers, game suppliers, licensing authorities, or hosting services.
• Unforeseen technical challenges or force majeure events beyond our reasonable control.

We will communicate any anticipated delays promptly and work with you to establish revised timelines. Delays caused by client-side factors do not entitle the client to refunds, penalties, or termination without payment for work completed.

7. Warranties and Disclaimers

We warrant that the software we develop will substantially conform to the specifications agreed upon in your service agreement for a period defined in that agreement following delivery ("Warranty Period"). During the Warranty Period, we will correct any material defects in the deliverables at no additional charge.

Except as expressly stated above, our services and deliverables are provided "as is" and "as available." To the fullest extent permitted by law, we disclaim all other warranties, whether express, implied, or statutory, including but not limited to:

• Implied warranties of merchantability, fitness for a particular purpose, and non-infringement.
• Any warranty that the platform will be uninterrupted, error-free, or completely secure.
• Any warranty regarding the results or revenue that may be obtained from the use of the platform.
• Any warranty that the platform will comply with all regulatory requirements in every jurisdiction where the client chooses to operate. Regulatory compliance is the sole responsibility of the client.

8. Limitation of Liability

To the maximum extent permitted by applicable law, in no event shall Turnkey Online Casino, its directors, employees, partners, agents, or affiliates be liable for any indirect, incidental, special, consequential, or punitive damages, including without limitation loss of profits, revenue, data, business opportunities, or goodwill, arising out of or in connection with your use of our services or deliverables, regardless of the theory of liability.

Our total aggregate liability arising out of or relating to these Terms or any service agreement shall not exceed the total fees actually paid by you to us for the specific project giving rise to the claim during the twelve (12) months preceding the event that gave rise to the liability.

These limitations apply even if we have been advised of the possibility of such damages and regardless of whether the remedy fails of its essential purpose.

9. Confidentiality

Both parties agree to maintain the confidentiality of any proprietary or confidential information disclosed during the course of the engagement. Confidential information includes, but is not limited to:

• Business plans, financial information, pricing structures, and strategic plans.
• Technical specifications, source code, architecture designs, and system documentation.
• Client lists, user data, marketing strategies, and trade secrets.
• Any information explicitly marked as confidential or that a reasonable person would understand to be confidential given the nature of the information and the circumstances of disclosure.

Confidential information shall not be disclosed to any third party without the prior written consent of the disclosing party, except as required by law or to authorized employees, contractors, or advisors who need access to perform their duties and are bound by equivalent confidentiality obligations. These confidentiality obligations survive the termination of any agreement between the parties.

10. Termination

Either party may terminate the service engagement under the following conditions:

• For Convenience: Either party may terminate with written notice as specified in the service agreement, subject to payment for all work completed up to the date of termination.
• For Cause: Either party may terminate immediately upon written notice if the other party materially breaches these Terms or the service agreement and fails to cure such breach within thirty (30) days of receiving written notice of the breach.
• Non-Payment: We may terminate or suspend services if the client fails to make payments when due and does not remedy the default within fifteen (15) business days of receiving notice.

Upon termination, the client shall pay for all work completed and expenses incurred up to the effective date of termination. Provisions relating to intellectual property, confidentiality, limitation of liability, and governing law shall survive termination of these Terms.

11. Governing Law

These Terms of Service and any disputes arising out of or in connection with them shall be governed by and construed in accordance with the laws of the jurisdiction specified in your service agreement. If no jurisdiction is specified, these Terms shall be governed by the laws of the jurisdiction in which the Company is incorporated.

Any disputes that cannot be resolved amicably shall be submitted to the exclusive jurisdiction of the courts in the applicable governing jurisdiction. Both parties agree to attempt to resolve disputes through good-faith negotiation before pursuing formal legal proceedings.

12. Changes to Terms

We reserve the right to modify or update these Terms of Service at any time at our sole discretion. When we make changes, we will revise the "Last updated" date at the top of this page. Material changes will be communicated to active clients via email or through a prominent notice on our website.

Your continued use of our website or services after any changes to these Terms constitutes your acceptance of the revised Terms. We encourage you to review these Terms periodically to stay informed of any updates. Existing service agreements in effect at the time of a change will be governed by the Terms in effect when the agreement was executed, unless both parties agree otherwise in writing.

13. Contact Information

If you have any questions, concerns, or requests regarding these Terms of Service, please contact us at:

Turnkey Online Casino
Email: salesgambitsoft@gmail.com

We will make every effort to respond to your inquiry in a timely manner.